Party A:
Party B:
In accordance with the Contract Law of People's Republic of China (PRC), Construction Law of People's Republic of China (PRC) and other relevant laws and regulations, and following the principles of equality, voluntariness, openness, honesty and credit, in order to clarify the rights, obligations and economic responsibilities of both parties in the construction process, the two parties reached the following agreement on engineering quality, safety production, construction period and other related matters through friendly negotiation, which shall be abided by jointly.
I. Overview of the Project
1. 1 project name: C3, C6 and C9# residential buildings in Yuquan Jiayuan, Laoting County
1.2 project site: site of former yangtiezhuang village in the north of Laoting county.
1.3 structural form: C3 and C6# are brick-concrete structures, and C9# is shear wall structure.
1.4 project scope: see the drawings for details of main body, decoration, water heating and electricity installation, etc.
1.5 Building area: 17026.49㎡ (subject to the actual drawing area).
1.6 commencement date:? 20 1 1.4. 1
1.7 completion date? 20**.5.3 1
Second, the project cost and payment method
2. 1 Temporary pricing of the project: the temporary pricing of the brick-concrete structure is 800 yuan/㎡, and the project cost is 869,254 ㎡ * 800 yuan = 6,954,000 yuan. The unit price of shear wall structure is 1000 yuan/㎡, and the project cost is 83.3395 ㎡ *1000 yuan = 8.334 million yuan. The total project price is 6,543,800 yuan+05,288,000 yuan (one thousand Wu Bai two hundred and eighty-eight thousand yuan). This fee is only used as the basis for paying the construction progress payment during the construction period, not as the settlement price.
2.2 Settlement method: The project quota is based on the unified national basic quota of construction projects in Hebei Province in 2008, the unified national budget quota of construction and installation projects in Hebei Province, the unified national budget of municipal projects in Hebei Province and the unified national consumption quota of architectural decoration projects in Hebei Province. It shall be implemented in accordance with the relevant provisions of the Code for Valuation of Construction Projects in Hebei Province, Cost Quota of Construction, Installation, Municipal Affairs and Decoration Projects in Hebei Province, and the new adjustment documents such as the Notice of the Housing and Urban-Rural Construction Reform Commission of Hebei Province on Adjusting the Unit Price of Comprehensive Employment in the Current Valuation Basis of Construction Projects. Other expenses are calculated according to the quota. Tower crane fees are charged for the entry, exit and installation of large machinery. Design changes and on-site visas shall be settled by the above settlement method.
2.3 Payment method and time of project progress payment: What are the specific ways to allocate funds by stages according to the project progress? . After the project is completed and accepted, 95% of the total price (total settlement price) will be allocated, and 5% will be kept as the quality warranty fund, which will be returned one year after the completion and acceptance. The project funds are all in cash.
2.4 Material supply and management: the materials supplied by Party A and the materials designated by Party A shall be adjusted according to the supply price of Party A and the price of designated materials at the time of settlement. If the unit price is inconsistent during the construction period, it shall be calculated according to the arithmetic average of the quantity of materials supplied and the unit price. The materials collected by Party B by itself are based on the cost information of Tangshan City, and the monthly arithmetic average of the cost information during the construction period where the project is located is taken as the material settlement unit price. The unit price of materials without cost information in Tangshan must be confirmed by Party A on site, and it will be regarded as the settlement unit price after confirmation.
Third, the project quality and requirements
3. 1 The project quality meets the requirements of design drawings and current national construction codes and standards.
3.2 The materials collected by Party B must meet the design requirements and the specifications and materials required by Party A. ..
3.3 All engineering quality problems caused by Party B's construction or material collection shall be borne by Party B, and Party A shall not bear any economic losses and responsibilities.
Fourth, the quality warranty period and warranty responsibility
4. 1 quality warranty period: the main structure is designed with reasonable service life, waterproof for five years and other two years.
4.2 Warranty responsibility: Within a reasonable service life, Party B shall be responsible for the personal and property losses caused by the project quality.
Verb (abbreviation of verb) safety responsibility and safety protection
5. 1 Party B must provide safety education to employees in accordance with the regulations on safety production management, do a good job in safety prevention, show certificates according to the requirements of relevant departments, conduct civilized construction and work safely, and prevent the occurrence of heavy casualties.
5.2 Party B must abide by the Law of People's Republic of China (PRC) on Work Safety, conscientiously implement the Regulations of People's Republic of China (PRC) and the State Council on Work Safety Management of Construction Projects, and implement work safety management in accordance with the laws, regulations, procedures, requirements and methods of the state and related industries, as well as the Standards for Construction Safety Inspection in People's Republic of China (PRC).
5.3 If the safety management of the construction party is not in place and industrial accidents occur, all responsibilities and expenses shall be borne by Party B, and Party A shall not bear any responsibilities.
The rights and obligations of party a with intransitive verbs
6. 1 Party A will charge 3% of the total project price as the project management fee, which will be deducted from Party B's project payment when allocating funds.
6.2 Party A has the right to supervise the construction progress, project quality and safe production, and correct and deal with the existing problems.
6.3 Provide construction drawings and make technical disclosure.
6.4 Assist Party B to coordinate with relevant construction units during the construction.
6.5 Pay the progress payment in time.
Seven. Rights and obligations of Party B
7. 1 Party B has the right to arrange the construction plan and specific matters of the project by itself and be responsible for them.
7.2 Standardize the construction in strict accordance with the drawings and the building requirements put forward by Party A, respect contracts and keep promises, and ensure the quality and time limit.
7.3 Adhere to safe production and civilized construction, and professional and technical personnel shall hold relevant certificates. Be responsible for the safety education and accident handling of the company's construction personnel. Accept the security inspection, urban construction, supervision and inspection of Party A. ..
7.4 If Party A fails to pay the project progress payment in time, Party B has the right to stop work or terminate the contract. In addition, Party A shall settle accounts according to the actual completed quantities. Party A shall be responsible for the losses caused by hunger.
Eight. responsibility for breach of contract
During the performance of this contract, if one party breaches the contract, it shall compensate the other party at 5% of the total project cost. If the construction cannot be carried out due to Party A's reasons (approval letter issued by Party A) or irresistible reasons, the construction period will be postponed accordingly.
Nine. Other supplementary matters:
X. Matters not covered in this contract shall be settled by both parties through consultation.
XI。 This contract shall come into effect as of the date of signature by both parties.
12. This contract is made in duplicate, with each party holding one copy.
Party A (signature): Party B (signature):
Representative (signature):? Representative (signature):
Year? Month? sun
Engineering construction contract (2)
Employer (Party A): (full name) Weihai Zhuo Yun Hotel Management Co., Ltd.
Contractor (Party B): (full name)? Shenzhen Li Nan Decoration Engineering Co., Ltd. Nanjing Branch
According to the Contract Law of People's Republic of China (PRC), the Bidding Law of People's Republic of China (PRC) and other relevant regulations, and following the principles of equality, voluntariness, fairness, honesty and credit, Party A and Party B have reached the following agreement on the contracting of this decoration project through consultation.
1 project overview
1. 1 Project name: Decoration Project of Weihai Zhuo Yun Hotel.
1.2 project location: west of weihai new industrial zone management Committee.
1.3 project content: joinery curtain box, piping and closet in the first area.
1.4 scope of contract: 1 joinery curtain boxes, pipes and closets.
1.5 contracting method: fixed unit price, with Party B contracting the work and materials.
1.6 engineering structure: frame structure.
1.7 Decorated building area: 26,806.7 square meters.
2 engineering quality
2. 1 The quality of this project shall conform to the national and industrial quality inspection standards, design standards or other standards agreed by both parties.
2.2 indoor environment agreed standard: code for indoor environmental pollution control of civil building engineering (GB 50325-200 1).
2.3 Construction quality acceptance standard: Unified Standard for Construction Quality Acceptance of Building Engineering (GB 50300-200 1) and relevant supporting engineering quality acceptance specifications and standards.
3 time limit for a project
3. 1 Total construction period: 60 days (calendar construction period, excluding Spring Festival holiday).
3.2 Commencement date: February 9, 20**.
3.3 Completion Date: April 7, 20**.
3.4 Delayed commencement: If Party B fails to start construction on schedule, it shall notify Party A in writing two days in advance. If Party A fails to reply within two days, it shall be deemed as agreeing to postpone the commencement, and the specific commencement date shall be agreed separately. If Party A does not agree to postpone the commencement, the construction period will not be postponed; If the commencement of construction needs to be postponed due to Party A's reasons, it shall be agreed by Party B, and the losses caused thereby shall be borne by Party A, and the construction period shall be postponed accordingly.
3.5 Suspension of construction (shutdown): If Party A requests Party B to suspend construction, it shall put forward handling opinions to Party B within 24 hours, and Party B shall properly protect the completed project. If Party A fails to put forward treatment suggestions in time, Party B may continue the construction, and the losses caused thereby shall be borne by Party A. If Party B requests to resume work, Party A shall give a reply within 12 hours. If Party A fails to reply on time, Party B may return to work on its own.
3.6 the construction period shall be postponed
3.6. 1 In case of any of the following circumstances, the construction period will be postponed, and Party B will not be responsible:
(1) Party A fails to provide the starting conditions as agreed in the contract.
(2) Increase of engineering quantity and design change.
(3) Party A fails to accept the concealed works on time.
(4) Party A fails to supply the materials and equipment provided by Party A on time as agreed in the contract.
(5) Construction cannot be carried out due to water and power failure for more than 48 hours due to reasons other than Party B..
(6) Party A fails to pay the project payment on time.
(7) The construction period is delayed because Party A or Party A's representative insists on the wrong instructions.
(8) Work stoppage caused by force majeure and other reasons not attributable to Party B. ..
3.6.2 In case of the above situation, Party B shall promptly notify Party A in writing. If the construction period is delayed due to Party B, Party B shall bear the responsibility and the construction period will not be postponed.
3.7 time limit for a project in advance
3.7. 1 The condition of early completion is to adopt feasible new technical measures, and any violation of process standards and cutting corners shall not be used as a means of early completion. If Party A requests to complete the project ahead of schedule, both parties shall sign an agreement on completion ahead of schedule, and Party A shall approve Party B's revised schedule and new technical measures within 2 days, and provide necessary conditions for speeding up the work progress.
3.7.2 The early completion agreement shall include the following contents:
(1) in advance.
(2) Technical measures taken by Party B ..
(3) Conditions provided by Party A for implementing new technical measures.
(4) The cost of implementing new technical measures increases.
4 design
4. 1 Provide design drawings and technical documents
Party B shall provide the design drawings required for construction. Provide Party A with as-built drawings after completion.
4.2 Design changes
4.2. 1 When Party A requests to change the design, it shall notify Party B 3 days before the construction of the divisional or sectional works. Party B shall immediately stop the construction and preparation activities of relevant parts.
4.2.2 Party A shall bear the losses caused by Party B's rework due to the design changes of the completed project.
4.2.3 Design changes shall be confirmed by Party A's representative through consultation, and Party B shall change the construction schedule, submit it to Party A for approval, and adjust the project price.
4.2.4 When design changes are involved, the design drawing provider shall provide the changed design drawings and material samples as the basis for pricing and construction.
5 Project price
5. 1 project price:
The bid price shall prevail, and the comprehensive unit price shall be implemented. If the comprehensive unit price cannot be implemented for the added projects, the consumption quota of Shandong construction projects in 2003 shall be implemented, and the fees shall be charged according to 53 yuan/quota man-days, and 48 yuan/quota man-days shall be used to find the price difference. According to the market price confirmed by both parties, the price of materials decreased by 2% after being audited by a qualified audit department. (See the letter of acceptance in the annex for details).
5.2 Approximate price of this project: RMB? Two hundred and fifty thousand yuan, 250,000.00 yuan, including the insurance premium of Party B for the project, the personnel involved in the project construction and the measures taken to complete the project. The specific total amount shall be subject to the final accounts of completion. After the completion settlement audit, a formal invoice will be issued for payment.
5.3 The project price can be adjusted under the following circumstances:
(1) Increase or decrease of quantities confirmed by Party A. ..
(2) Design change or engineering negotiation confirmed by Party A. ..
(3) One of other conditions for extending the construction period agreed in "3.6. 1".
(4) Other increase, decrease or adjustment agreed by both parties.
5.4 Payment of Project Price
5.4. 1 down payment for the project
5.4. 1. 1 Party B shall provide relevant quality acceptance records to Party A after completing all concealed works. With the approval of the supervisor, Party A shall pay a deposit of 45% of the total project price to Party B, with the deposit amount of 1 12500.00 Yuan, in words: one hundred and twelve thousand Wu Bai Yuan only. The payment time is within 5 working days after the mid-term acceptance of the project. If Party A fails to pay the deposit as agreed, Party B may notify Party A in writing. If Party A still fails to pay within 5 working days after receiving the notice, Party B may suspend the construction.
5.4. 1.2 The interim standard of the project is that all concealed works are completed and accepted by the supervisor.
5.4. 1.3 The advance payment for the project shall include the negotiation payment (such as design change, increase or decrease of engineering quantity, etc. ).
5.4. 1.4 Without the consent of the supervisor, the quantities increased by Party B beyond the design drawings and the quantities increased by rework due to Party B shall not be measured.
5.4. 1.5 After Party B agrees in writing and specifies the deferred payment date, Party A may postpone the payment; If Party A delays payment, the interest payable for the project shall be calculated within 5 days from the date of confirmation of the delay (calculated according to the bank loan interest rate for the same period).
5.4.2 The project shall be handed over to Party A for use after completion and acceptance. Party B shall provide Party A with construction quality certification documents, completion settlement audit and complete settlement data, and Party A shall pay 50% of the total project price to Party B within 5 working days after being verified by Party A and the supervisor. The payment time is within 5 working days after Party B provides all engineering materials. Party A shall keep 5% of the total project price as warranty money. The warranty payment shall be paid to Party B within 5 working days after Party B completes the project warranty as agreed.
6 supply of materials and equipment
6. 1 For the materials provided by Party A in this project, Party B shall specify the ordering time and mobilization time in the construction progress plan, and timely track whether Party A orders and mobilizes within the agreed time.
6.2 The materials, equipment, finished products and semi-finished products purchased by Party B in this project shall be purchased according to the standards of bidding materials samples, and the quality and environmental protection certificates of materials, equipment and products shall be provided. Party B shall be responsible for the quality of the purchased materials and equipment. If the purchased materials are inconsistent with the samples, Party A and the supervision unit have the right to ask Party B to replace them. If the replacement is still inconsistent with the sample, Party A has the right to terminate the construction contract with Party B, and all losses caused thereby shall be borne by Party B. The losses caused by Party B to Party A shall be borne by Party B. ..
6.3 The materials and equipment purchased by Party A for Party B shall be notified to the other party before reaching the designated place as agreed, and both parties shall make equal acceptance of the materials and equipment. After the materials and equipment supplied by Party A are qualified, Party B is responsible for keeping them.
6.4 The main materials of this project shall be selected by both parties. The samples are sealed after acceptance by both parties, which will serve as the material standard for material supply and completion acceptance.
6.5 The main engineering materials provided by both parties shall conform to the Limits of Hazardous Substances in Interior Decoration promulgated by AQSIQ.
Seven representatives from both sides are stationed in this project.
7. 1 The representative of Party A in this project is Wang.
7.2 The project manager assigned by Party B to this project is Qian Yingjiu, who is the representative of Party B in this project.
7.3 The representatives of both parties stationed in the construction site of this project shall exercise the rights and perform the obligations of their respective senders according to this contract.
7.4 Any written conditions and instructions issued by Party A's representative to Party B's project manager within the scope of authorization shall be implemented by the project manager.
8 rights of both parties
8. 1 Rights of Party A
8. 1. 1 has the right to change the representative stationed at the construction site according to the needs of the project, but it shall notify Party B in writing three days in advance. After the replacement, the rights and responsibilities of the representatives remain unchanged.
8. 1.2 has the right to supervise Party B's performance of various contractual obligations.
8. 1.3 has the right to examine and approve the construction progress plan prepared by Party B. ..
8. 1.4 has the right to supervise the project quality and construction progress, and participate in materials and equipment, concealed works, divisional works and completion acceptance.
8.2 Rights of Party B
8.2. 1 has the right to replace the representative stationed at the construction site of this project according to the needs of the project, but it shall notify Party A in writing three days in advance, and the rights and responsibilities of the representative after replacement will remain unchanged.
8.2.2 Have the right to supervise Party A's performance of various contractual obligations.
8.2.3 When Party B's representative thinks that the instructions of Party A's representative are unreasonable, he has the right to submit a written report on the modification instructions to Party A's representative within 24 hours after receiving the instructions from Party A's representative. If Party A's representative insists on carrying out the original instruction, Party B's representative shall carry it out, but Party A shall bear the expenses and losses caused to Party B due to the instruction error.
9 Obligations of both parties
9. 1 obligations of party a
9. 1. 1 Pay the project payment to Party B as agreed.
9. 1.2 Assist Party B to handle the construction permit and other approval documents required for construction.
9. 1.3 Organize Party B to conduct the blue prints.the design and technical disclosure with the design unit and supervision unit.
9. 1.4 provide the construction site, remove the obstacles that affect the construction, bear the corresponding measures and expenses of Party B's construction, and do not vacate the site.
9. 1.5 Provide technical information on the main structure of the house and the mechanical and electrical equipment of water, electricity and heating.
9. 1.6 Provide water and electricity needed for construction to ensure the needs during construction.
9. 1.7 Coordinate the relationship between professional construction units on the construction site to ensure the orderly progress of the project.
9. 1.8 Strictly implement the relevant provisions of national production safety and environmental protection.
9. 1.9 In order to ensure the safety of the building structure, the decoration works in the original building shall not have the following acts:
(1) Change the main body and load-bearing structure of the house at will.
(2) Destroy the waterproof layer on the ground and pipeline facilities such as heat, heating and gas.
(3) Other behaviors that force Party B to operate illegally.
If the above contents must be involved, there shall be design drawings involving the transformation scheme, and a written explanation for safe use shall be issued.
9.2 Obligations of Party B
9.2. 1 Formulate and organize the implementation of the construction progress plan.
9.2.2 Comply with the management regulations of relevant government departments on traffic, construction noise, environmental protection and safety in production on the construction site.
9.2.3 In the process of construction, if any situation and matters affecting the performance of this contract and other hidden dangers are found, Party A shall be informed in writing in time so that Party A can deal with them in time. If Party A fails to fulfill this obligation, it shall bear the responsibilities and losses caused thereby.
Safe construction
9.2.3. 1 Strict safety protection and fire prevention measures shall be taken according to relevant regulations, and personnel and property losses caused by poor management shall be borne. Losses not caused by Party B's responsibility shall be borne by the corresponding responsible person.
9.2.3.2 must insure the project and the personnel involved in the construction of the project, and all expenses and responsibilities caused by safety accidents during the construction of the project and personal safety accidents of Party B's construction personnel shall be borne by Party B. ..
9.2.3.3 should provide guards, protection, lighting and fences for maintenance and construction according to engineering and safety requirements. During the construction of power equipment, high-voltage lines, underground pipelines, inflammable, explosive, toxic and harmful areas and temporary traffic arteries, Party A shall negotiate with Party A on safety protection measures, which shall be implemented after Party A agrees, and the protection expenses shall be borne by Party A.. ..
9.2.3.4 should formulate special safety and fire prevention measures to ensure the property and personal safety of buildings that are not vacated and continue to be used. The above measures shall be reported to Party A for approval, and Party A shall bear the corresponding expenses.
9.2.4 Before the completed project is officially delivered to Party A, Party A is responsible for the protection of the completed project.
9.2.5 Be responsible for the cleaning of the construction site, in line with the relevant provisions of environmental sanitation management.
10 project acceptance
10. 1 Acceptance of concealed works: Party B shall notify Party A's representative (supervision engineer) in writing within 24 hours after passing the self-inspection. Party B can conceal and continue the construction only after the acceptance is qualified and the inspection record is signed by Party A's representative (supervision engineer).
10.2 completion acceptance
If the 10.2. 1 project meets the completion acceptance conditions, Party B shall provide Party A with the completion acceptance report, completion data and completion drawings according to the relevant provisions of national completion acceptance. Party A shall organize acceptance within 7 days after receiving the report, and notify Party B in writing to agree or put forward amendments within 2 days after acceptance, and both parties shall agree on the revision period according to the revised quantities. Party B shall make the modification according to Party A's opinions and bear the modification expenses caused by its own reasons.
10.2.2 if party a fails to organize acceptance or put forward modification opinions within the time limit, it shall be deemed that the project is qualified, and the acceptance shall be agreed, and the completion settlement formalities shall be handled.
10.2.3 completion date refers to the date when Party B issues the completion acceptance report and it is confirmed as qualified by Party A and the supervisor. The completion date is also considered as the warranty start date.
10.2.4 Party A shall not use the project that fails to pass the completion acceptance or fails to pass the completion acceptance; If Party A forcibly uses it, it will be deemed as qualified after the completion acceptance, and the quality responsibility and other responsibilities arising therefrom shall be borne by Party A. ..
10.2.5 If part of the project cannot be completed temporarily due to special reasons, both parties may sign a project completion agreement.
10.2.6 completion settlement: after the completion report is approved by party a, party b shall submit the completion settlement report and complete settlement data to party a in accordance with relevant national regulations or contractual stipulations. Party A shall, within 15 working days from the date of receiving the report and settlement data, review and confirm, pay the final payment of the project to Party B as agreed in the contract, and both parties shall go through the project handover procedures. If Party A fails to handle the completion settlement within the time limit without justifiable reasons, it shall bear the corresponding storage fee and interest loss of Party B. ..
1 1 liability for breach of contract
1 1. 1 If Party A and Party B fail to perform their obligations as agreed in the contract, they shall bear corresponding liabilities for breach of contract, including paying liquidated damages and compensating the other party for economic losses caused by breach of contract.
1 1.2 If Party A fails to pay the project advance payment, project progress payment and completion settlement payment on time, () Party A shall pay Party B a penalty of 3‰ for each day of delay.
1 1.3 If the construction period is delayed due to Party B's responsibility, Party B shall pay Party A a penalty of 3‰ of the contract amount for each day of delay; Party B shall pay the liquidated damages for delay to Party A, and at the same time, it shall also pay Party A the extra remuneration for the delayed supervision caused by Party B.. ..
1 1.4 If the project quality and indoor environmental pollution control are not up to standard due to Party B's responsibility, Party B shall thoroughly rework and repair the unqualified part of the project and comprehensively treat the unqualified indoor air quality. If the project is delayed due to the above reasons, it shall be regarded as the delay of the construction period.
1 1.5 After the breaching party assumes the liability for breach of contract, both parties shall continue to perform the contract in order to maintain the continuity and integrity of the project, except that the contract is terminated under the following circumstances:
(1) The contract cannot be continued.
(2) Both parties agree to stop the construction.
(3) Mediation requires to stop the construction.
(4) The arbitration requires to stop the construction.
(5) The court requested to stop the construction.
12 others: insurance, guarantee, warranty, etc. It can be separately agreed by both parties in writing as an annex to this contract.
13 force majeure: if the contract cannot be performed due to force majeure, the liability shall be exempted in part or in whole according to the influence of force majeure, unless otherwise stipulated by law. If one party fails to perform the contract due to force majeure, it shall notify the other party in time to reduce the possible losses to the other party, and shall provide proof within a reasonable time.
14 dispute settlement method: disputes arising under this contract shall be settled by both parties through consultation or by applying for mediation; If negotiation or mediation fails, the following methods (1) shall be adopted:
(1) bring a lawsuit to the people's court where the project is located according to law.
(2) Submit to the Arbitration Commission for arbitration.
15 contract comes into effect: this contract comes into effect as of the date of signature and seal by both parties.
16 the original of this contract is in triplicate, with each party holding one copy; Copy? Copy, Party A? Copy, Party B? Share it.
17 supplementary agreement:
17. 1 This project requires Party B to carry out the construction in strict accordance with the technical standards in the bidding documents. If Party A's personnel find that Party B fails to carry out the construction according to the technical standards in the bidding documents, Party A may terminate the construction contract with Party B at any time.
Party A (signature): Party B (signature):
Address:? Address:
Representative: representative:
Telephone:? Contact telephone number:
Bank of deposit:? Bank of deposit:
Account number: Account number:
Signing time:? Signature time:
Signing place: Signing place:
Engineering construction contract (3)
Owner (full name): Jiangxi Kang Sheng Investment Co., Ltd.
Contractor (full name): Hu
The employer and the contractor signed the quality warranty of Fuyang Spring Commercial and Residential Quarter 15#, 20# and 22# (full name of the project) through consultation in accordance with the Building Law of People's Republic of China (PRC), Regulations on Quality Management of Construction Projects and Measures for Quality Warranty of Housing Construction Projects.
A, the scope and content of engineering quality warranty
During the quality warranty period, the contractor shall undertake the quality warranty responsibility of this project in accordance with the management provisions of relevant laws, regulations and rules and the agreement of both parties.
The scope of quality warranty includes basic engineering, main structure engineering, roof waterproof engineering, leakage prevention of toilets, rooms and external walls with waterproof requirements, heating and refrigeration systems, electrical pipelines, water supply and drainage pipelines, equipment installation and decoration engineering and other projects agreed by both parties. The specific warranty contents are as follows:
Civil engineering (foundation, main structure, roof waterproofing) decoration, water and electricity installation.
Second, the quality warranty period
According to the Regulations on Quality Management of Construction Projects and related regulations, both parties agree that the quality warranty period of this project is as follows:
1, the reasonable service life of foundation engineering and main structure engineering as specified in the design documents;
2, roofing waterproof project, the bathroom, room and exterior wall waterproof requirements for leakage? Wu? Year;
3. What is the decoration project? One? Year;
4, electrical pipes, water supply and drainage pipes, equipment installation project for? Hey? Year;
5, residential water supply and drainage facilities, roads and other supporting projects? One? A few years.
6. The warranty period of other projects is as follows:
The quality warranty period is calculated from the date of project completion acceptance.
Third, the quality warranty responsibility
1 belongs to the scope and content of the warranty project, and the contractor shall send someone to guarantee it within 7 days from the date of receiving the maintenance notice. If the contractor fails to send someone for warranty within the agreed time limit, the employer may entrust others to repair it.
2. In case of emergency repair accident, the contractor shall immediately arrive at the scene of the accident for emergency repair after receiving the accident notice.
3. The quality problems involving structural safety shall be reported to the local construction administrative department immediately, and safety precautions shall be taken in accordance with the provisions of the Measures for Quality Assurance of Housing Construction Projects; The original design unit or the design unit with corresponding qualification grade shall put forward the warranty scheme, and the contractor shall implement the warranty.
4. After the quality warranty is completed, the owner will organize the acceptance.
Fourth, the warranty cost.
1, the project quality warranty gold agreed in this project is 3% of the final project price, and the warranty amount is? (in words)
2. The warranty expenses shall be borne by the responsible party causing quality defects.
Verb (short for verb) others
Other project quality warranty matters agreed by both parties: the warranty amount shall be paid to the contractor in one month after the completion and acceptance of the project, and the contractor will continue to guarantee the remaining warranty projects free of charge.
The quality warranty of this project shall be signed by both the employer and the contractor of the construction contract before the completion acceptance, and shall be taken as an annex to the construction contract, and shall be valid until the warranty period expires.
Employer (official seal): Contractor (official seal):
Legal representative (signature):? Legal representative (signature):
Year, month and day? date month year